Compare moats
Up to three covered companies, band by band. Every call is a curated editorial judgment, never a disclosed figure — and every band carries its cited basis.
| Cipher Mining | IREN | Iron Mountain | |
|---|---|---|---|
| Moat rating | none Cipher (renamed Cipher Digital Inc. on 20 February 2026) holds signed, credit-supported leases but has not yet shown that they amount to a durable advantage. Its 2025 Form 10-K (filed 2026-02-24) says "Through the end of 2025, our revenue has been derived from mining bitcoin". Its Q2 2026 business update (2026-08-04, Exhibit 99.1, https://www.sec.gov/Archives/edgar/data/1819989/000181998926000038/q226_earningsxprxdraftxvf.htm) reported "Q2 2026 Revenue of $25 million", and its first HPC rent began only in August 2026 at Black Pearl. The 10-K's own risk factors describe a contested market. They say "There has been an increasing number of businesses constructing HPC data centers, which has resulted in increasing competition and pricing pressure that may cause us to reduce our pricing in order to remain competitive", that "our data centers are single-tenant properties", and that lessees "will have the right to terminate the lease if there are significant delays in the completion of construction". At Barber Lake, where the 10-K targeted Phase I delivery "by September 30, 2026", a September 2026 amendment, made "In connection with change orders and the continued evolution of tenant requirements", moved data-hall deliveries to the fourth quarter of 2026 through the first quarter of 2027. Under it, Cipher "will bear the first $359.3 million of costs in excess of the initial budgeted amount" (2026-09-25). There is real counter-evidence: a 15-year Amazon lease, a Google-backstopped Fluidstack lease whose contracted life a "leading AI lab" extended to 20 years, and a third lease with an investment-grade hyperscale tenant. Until that capacity is delivered and paying rent, though, a moat is not shown, so the band is none. | none The FY2026 10-K (filed 2026-08-27) shows IREN holds an input the industry competes on: it names 'access to secured and energized power' first among what it believes are the principal competitive factors in its industry, and reports 'executed grid connection agreements, letters of agreement or equivalents representing approximately 5GW of total power capacity' in the United States, Canada, Spain and Australia as of June 30, 2026. It does not claim an advantage over rivals in that input. It says 'Certain competitors may have access to more competitively priced power, a greater access to power and a better capacity to timely secure grid connections,' and 'Many of our competitors have greater financial, technical or commercial resources, longer cloud operating histories or larger customer bases, compared to us.' Operating AI Cloud Services capacity was approximately 40MW at June 30, 2026, and the stored XBRL fundamentals from this 10-K show an FY2026 operating loss of about $1,046.7M on revenue of about $707.0M, so no durable advantage is yet demonstrated. | narrow Iron Mountain's physical-records franchise shows a real switching-cost advantage, but the FY2025 Form 10-K also describes a slowly shrinking need for it, and the growth businesses compete in open markets. On the advantage side, an independent record: the Department of Justice complaint published in the Federal Register on 2016-04-11 (https://www.federalregister.gov/documents/2016/04/11/2016-08210/united-states-v-iron-mountain-inc-and-recall-holdings-ltd-proposed-final-judgment-and-competitive) stated that "Iron Mountain is the largest RMS company in the United States" and that "Taken together, permanent withdrawal fees and other withdrawal restrictions make it difficult for a new RMS entrant to win customers away from existing RMS vendors." The 2025 10-K reports more than 740 million cubic feet stored, says "we have consistently experienced strong customer retention levels", and shows the Global RIM segment's Adjusted EBITDA margin at 44.7% in 2025 against 44.6% in 2024. On the limiting side, Item 1A says "Our Records Management and Data Management service revenue growth is being negatively impacted by declining activity rates as stored records and tapes are becoming less active and more archival" and "A significant shift by our customers to storage of data through non-paper or non-tape-based technologies, whether now existing or developed in the future, could adversely affect our businesses." In data centres the 10-K says it competes with "numerous data center developers, owners and operators, many of whom own properties comparable to ours". A strong, regulator-documented lock-in on a physical market the company itself expects only to hold steady, plus growth arms without that lock-in, is a narrow moat rather than a wide one. |
| Moat type | none No moat source is demonstrated yet. Switching costs are the most likely candidate, since the leases are long (15 years at Black Pearl; Barber Lake now a 20-year contracted life) and each site has a single tenant. But the 10-K says tenant guarantees "will only be effective after rent commencement under such leases and are subject to certain limitations", and by August 2026 rent had begun at only one site. The advantages the 10-K claims are the company's own. It speaks of "industry-leading expertise in originating and securing industrial-scale, greenfield data center sites" and of securing West Texas land "on more favorable terms than in more established data center markets". The same document says "there is significant competition for power capacity and energized facilities". Intellectual property is modest: "four granted United States patents and one issued patent in Taiwan". With 66 full-time employees, Cipher has no scale advantage over the competitors it names: CoreWeave, Digital Realty, Equinix, Vantage Data Centers and Aligned Data Centers. | none The FY2026 10-K's asserted advantage is control from owning its data centers, 'including the associated land, grid connections and substations', which it believes allows it 'to benefit from more sustainable cash flows and operational flexibility relative to operators that rely upon third-party colocation services or short-term land leases'. Its only scale language is a belief that its 'procurement scale, deployment experience and direct control over the data center layer' lets it bring new compute into service 'rapidly and at scale', a deployment-speed claim, and it 'generally target[s]' regions with 'low-cost and attractive renewable energy sources', a siting target rather than a demonstrated cost position. It does not claim a cost or scale lead: it says 'Many of our competitors are larger, have longer operating histories and significantly greater resources than we do' and that certain competitors 'may have access to more competitively priced power, a greater access to power and a better capacity to timely secure grid connections.' There is no network effect or lock-in either, since existing contracts have 'terms ranging from month to month up to five years'. No enumerated moat source is grounded. | switching costs The advantage is the cost and friction of moving stored records. The 10-K's Item 1A says that "if we are successful in winning record storage customers from competitors, the process of moving their stored records into our facilities is often costly and time consuming", and its notes record payments made "to a customer in order to terminate the customer's storage of records with its current records management vendor" as customer inducements. The DOJ complaint (https://www.federalregister.gov/documents/2016/04/11/2016-08210/united-states-v-iron-mountain-inc-and-recall-holdings-ltd-proposed-final-judgment-and-competitive) describes the mechanism: "Customer contracts also often impose a cap on the number of boxes per month that a customer may permanently remove from a RMS vendor's facility, such that a switch to a new RMS vendor may take several months to complete", and a new vendor "will have to offer to pay the fees to induce the customer to switch". Scale helps, since the 10-K says "the majority of our competitors operate in only one market or region", but the filing's own account of what keeps customers is retention and the cost of leaving, which makes switching costs the primary source. |
| Leadership | fast follower No independent share or rank was found. The 10-K names CoreWeave, Digital Realty, Equinix, Vantage Data Centers and Aligned Data Centers as competitors, along with miners that have "signed leases with hyperscalers and HPC tenants": Hut 8, IREN, TeraWulf, Core Scientific and Applied Digital. Cipher has signed hyperscale-grade tenants (Amazon; Fluidstack with a Google backstop; a third investment-grade hyperscaler) but delivered its first HPC capacity only in August 2026 (Q2 2026 update). That makes it a fast follower. Its self-description as "a leading developer, owner, and operator of industrial-scale data centers" is the company's own claim and is not counted. | behind The 10-K lists IREN's competitors as hyperscalers (Amazon Web Services, Google Cloud, Microsoft Azure, Oracle Cloud) and specialized AI Cloud Services providers (CoreWeave, Nebius, Crusoe, Lambda, Nscale, SpaceX and others). It says IREN began providing AI Cloud Services in 2024 and cites its 'shorter operating history in AI Cloud Services relative to some competitors', and states 'Some of our competitors have longer operating histories, larger customer bases, more comprehensive IP portfolios and patent protections, more design wins, and greater financial, sales, marketing and distribution resources than we do.' Operating AI Cloud Services capacity was approximately 40MW at June 30, 2026. The filing describes a smaller, later entrant that trails some competitors on operating history, customer base and resources, with its progress so far resting on two anchor contracts (a ~$9.7B five-year Microsoft agreement and a ~$3.4B five-year NVIDIA contract) rather than any claimed category position. | clear leader The band applies to records management, the Global RIM segment that produced $5,291,481 thousand of 2025's $6,901,737 thousand revenue. Independent evidence: the DOJ complaint published in the Federal Register on 2016-04-11 (https://www.federalregister.gov/documents/2016/04/11/2016-08210/united-states-v-iron-mountain-inc-and-recall-holdings-ltd-proposed-final-judgment-and-competitive) stated "Iron Mountain is the largest RMS company in the United States", with fiscal 2014 worldwide revenues of "approximately $3.1 billion", and called Recall, with 2014 revenues of "approximately $836.1 million", "the second-largest RMS company in the United States"; the FY2025 10-K lists property "acquired in connection with our acquisition of Recall Holdings Limited". The 2025 10-K adds, in the company's own words, that "the majority of our competitors operate in only one market or region". The independent source is from 2016 and covers the United States only. Iron Mountain did go on to acquire Recall, but the proposed final judgment in the same notice required it to divest "Recall RMS assets in all fifteen geographic markets identified in the Complaint", thirteen of them to Access CIG, which the notice called "currently the third-largest RMS provider in the United States", so Recall's business was not absorbed whole. This leadership does not extend to data centres, where the Global Data Center segment's $803,429 thousand of 2025 revenue compares with total revenue of $9,217,000,000 at Equinix (https://www.sec.gov/Archives/edgar/data/1101239/000110123926000032/0001101239-26-000032-index.htm) and $6,112,692,000 at Digital Realty (https://www.sec.gov/Archives/edgar/data/1297996/000110465926015365/0001104659-26-015365-index.htm) in stored fundamentals from their FY2025 10-Ks. |
| Pricing power | weak The 10-K says competition "has resulted in increasing competition and pricing pressure that may cause us to reduce our pricing in order to remain competitive". It adds that if customers cut usage "we may be compelled to lower our prices or risk losing a significant customer". At Barber Lake, Cipher agreed to absorb "the first $359.3 million of costs in excess of the initial budgeted amount", with the tenant reimbursing "50% of any such costs above that amount" (2026-09-25, Exhibit 99.1, https://www.sec.gov/Archives/edgar/data/1819989/000181998926000043/barberlakeleaseamendmentpr.htm). Its one input-cost edge is specific to mining: Odessa's power costs about 2.8 c/kWh under the Luminant contract, available "until at least July 2027". A landlord that concedes cost overruns to its tenants has weak pricing power. | weak The 10-K's risk factors state 'Our competitors' products, services and technologies may be cheaper or provide better functionality or features than ours, which has resulted and may in the future result in lower-than-expected selling prices or demand for our products.' They also say long-term contract pricing 'is generally fixed or agreed at the time of contracting', so if market pricing for comparable capacity rises during a contract's term 'we will not benefit from those increases with respect to capacity already committed under our existing long-term contracts', and that if customers suffer a downturn or discontinue its services it 'may be compelled to offer more flexible terms, lower our prices or risk losing a significant customer.' The stored XBRL fundamentals from this 10-K show FY2026 revenue of about $707.0M against an operating loss of about $1,046.7M, so there is no margin record yet that evidences pricing power. | strong In records, growth comes from price on steady volume. MD&A attributes Global RIM "organic storage rental revenue growth driven by revenue management" (organic storage rental growth of 5.4% in 2025), while Item 1A says volumes "were relatively steady in 2025" and "Our organic revenue growth has been positively impacted by our ability to effectively introduce, expand and monitor revenue management. If we are not able to continue and effectively manage pricing, our results of operations could be adversely affected". The segment's Adjusted EBITDA margin was 44.7% in 2025 against 44.6% in 2024. In data centres MD&A cites "improved pricing" and "a 620 basis point increase in Adjusted EBITDA Margin reflecting recent lease commencements, improved pricing and cost containment", to 51.8% from 45.6%. The limits: Item 1A says that on power costs "we may be limited in our ability to, or may not always choose to, pass these increased costs on to our customers", and the 2016 DOJ complaint (https://www.federalregister.gov/documents/2016/04/11/2016-08210/united-states-v-iron-mountain-inc-and-recall-holdings-ltd-proposed-final-judgment-and-competitive) found that where Iron Mountain and Recall met, they "competed aggressively against one another for customers, resulting in lower prices for RMS". Adjusted EBITDA margin is a non-GAAP measure, and the Q2 2026 release (https://s204.q4cdn.com/148941814/files/doc_financials/2026/q2/FINAL-Q2-2026-Earnings-Press-Release.pdf) shows it at 35.8% for the company against 36.7% a year earlier. |
| Summary | Cipher built bitcoin mining data centres in Texas and is now developing single-tenant AI and HPC campuses for lease to hyperscalers. Its 10-K reports a portfolio of "4.2 gigawatts ("GW") of capacity across 10 sites". It lists a 15-year Amazon Web Services lease for about 300 MW of turnkey capacity at Black Pearl and a Fluidstack lease at Barber Lake (300 MW gross) under which Google "has agreed to backstop certain obligations of Fluidstack". It describes bitcoin mining at Odessa on a Luminant power contract at about 2.8 c/kWh. In 2026 it signed a third campus lease "with an investment-grade Hyperscale tenant" (Q1 2026 update, 2026-05-05), delivered first Black Pearl capacity in August "two months ahead of the original schedule" with rent commenced, and fully funded its Stingray development with a bond (Q2 2026 update). On 2026-09-25 it said Barber Lake's contracted life was extended from 10 to 20 years, taking contracted revenue at the site "from $3.8 billion to over $9 billion". The 10-K says Odessa was "the first bitcoin mining data center awarded the Management and Operations, or M&O, Stamp of Approval award from the Uptime Institute", which is independent recognition of how the company operates. Against this, the latest quarter's revenue was still bitcoin mining and fell to $25 million. The 10-K describes growing "competition and pricing pressure", single-tenant concentration, and termination rights for construction delays. The Barber Lake schedule was reset, and Cipher absorbs the first $359.3 million of cost overruns. Cipher's contracted pipeline is substantial, but a competitive advantage is not yet demonstrated, so it is rated as having no moat. That could change to narrow once its leased campuses are delivered and paying rent. | Per its FY2026 10-K, IREN is a vertically integrated AI Cloud Services platform that owns the data center, compute and software layers, underpinned by executed grid connection agreements, letters of agreement or equivalents representing ~5GW and a further multi-GW development pipeline. Its commercial record is concentrated: a five-year Microsoft agreement (~$9.7B total contract value, Horizon 1 delivered and accepted in August 2026, Horizons 2-4 targeted for delivery in phases in calendar Q4 2026) and a five-year ~$3.4B NVIDIA cloud contract together make up a substantial majority of contracted revenue. It holds NVIDIA Preferred Partner and Exemplar Cloud status (HGX B300 and GB300 NVL72) and a strategic partnership intended to support the deployment over time of up to 5GW of NVIDIA DSX-aligned infrastructure, which the filing cites among arrangements that are non-binding or subject to conditions, with no assurance as to the extent of deployments. Against that, the filing names hyperscaler and specialized competitors (AWS, Google Cloud, Azure, Oracle, CoreWeave, Nebius, Crusoe, Lambda, Nscale, SpaceX), many of which it says have greater resources, customers that can use or develop their own solutions, and possible delays to Texas energization from changes to ERCOT's Batch Zero procedures, so the power position is not a demonstrated advantage over rivals and its value depends on execution. | Iron Mountain stores and manages physical records for, per its FY2025 10-K, more than 240,000 customers in 61 countries, "including approximately 95% of the Fortune 1000", with "no single customer accounting for more than approximately 3% of revenue". Revenue was $6,901,737 thousand in 2025, of which the Global RIM segment contributed $5,291,481 thousand and the Global Data Center segment $803,429 thousand. The records business is the moat. Storage rental agreements "generally range from one to five years in length", the company says it has "consistently experienced strong customer retention levels", and a 2016 Department of Justice complaint described Iron Mountain as "the largest RMS company in the United States" and permanent withdrawal fees as a barrier to rivals winning customers. That lock-in shows up as pricing: MD&A attributes Global RIM storage growth to "revenue management" while Item 1A says volumes "were relatively steady in 2025". The threat is substitution: activity is declining as records become "less active and more archival", and a shift to non-paper storage "could adversely affect our businesses". The growth arms sit outside that moat. The company operated 31 data centers across 21 markets with 488 MW of capacity approximately 97% leased and a weighted average lease expiration of 10.3 years, counts "five of the largest global hyperscalers among our customers", and on 2026-08-05 reported data center leasing of 110 megawatts year to date and second-quarter revenue of $2.0 billion, up 18.5%. But in data centres it competes with operators owning "properties comparable to ours", and in asset lifecycle management with hyperscalers' own programmes. A durable switching-cost franchise in a market expected only to hold steady, funding growth businesses that compete on power, location and price, is a narrow moat. |
| Chain position | Cipher develops single-tenant, powered data-centre campuses for hyperscale and AI tenants: Amazon at Black Pearl, Fluidstack (backstopped by Google) at Barber Lake, and an unnamed investment-grade hyperscaler at a third campus. Meanwhile it winds down bitcoin mining. | Downstream AI-cloud operator: owns grid-connected data centers and deploys NVIDIA/AMD GPU systems it rents to hyperscalers, frontier labs, AI developers and enterprises (anchor customers Microsoft and NVIDIA). | In the AI build-out Iron Mountain is a landlord and a recycler. It leases data center capacity to hyperscale customers, with "five of the largest global hyperscalers among our customers", and its ALM business "provides hyperscale and corporate IT infrastructure managers with services and solutions that enable the decommissioning, data erasure, processing and disposition, and recycling or sale of IT hardware and component assets". Upstream, Item 1A says "We rely on third parties to provide power to our data centers" and that construction depends on "one or more design firms, general contractors, and associated subcontractors". |
| Products (share / barrier) |
|
|
|
| Long-horizon vote | -0.06 at weight 0.20 · swarm bearish Editorial prior, not backtested. | -0.20 at weight 0.20 · swarm bearish Editorial prior, not backtested. | +0.24 at weight 0.20 · swarm neutral Editorial prior, not backtested. |